Terms of Service

Effective Date: 10 January 2026

These Terms of Service (“Terms”) govern your use of Rewilt’s website, intake forms, and professional services. By submitting an intake form, booking a call, or engaging Rewilt for services, you agree to these Terms.

1. Definitions
   1. “Rewilt,” “we,” “our,” or “us” means Fromtribe OÜ, a private limited company registered in Estonia (registry no. 17336307), trading as Rewilt.
   2. “Client,” “you,” or “your” means any individual or business engaging Rewilt for services.
   3. “Services” means professional website design, development, automation, and related digital services.
   4. “Project” means a defined scope of Services agreed in writing.
   5. “Third-Party Services” means platforms or tools not owned or operated by Rewilt.
2. Nature of Services
   1. Rewilt provides professional consulting, design, and development services for businesses. 
   2. Rewilt is not a SaaS provider, marketing agency, hosting provider, or business broker. 
   3. Rewilt does not guarantee specific business results (including revenue, rankings, conversions, or leads) unless explicitly stated in a written agreement. 
   4. Any examples, projections, or performance references are illustrative only.
3. Engagement Process
   1. Engagement begins with submission of an intake or qualification form and, if applicable, a scoping call. 
   2. A Project becomes binding only once scope, timeline, and pricing are confirmed in writing, and the first agreed payment milestone is received. 
   3. Project timelines assume timely feedback, approvals, and material delivery from the Client. Delays caused by the Client pause timelines without penalty to Rewilt. 
   4. Rewilt reserves the right to decline Projects that are not a fit for its delivery model.
4. Fees, Payments, and Invoicing
   1. Fees are fixed per Project unless otherwise agreed in writing. 
   2. Payments are due according to the agreed milestone schedule and are considered received when funds are cleared in the Company’s account (e.g., via Stripe). 
   3. All fees are exclusive of VAT, sales tax, or similar taxes unless stated otherwise. 
   4. Late payments may pause work until payment is received.
5. Third-Party Services
   1. Rewilt may integrate or rely on Third-Party Services (e.g., hosting, payment systems, scheduling tools). 
   2. Rewilt is not responsible for the availability, performance, security, or changes of Third-Party Services. 
   3. The Client agrees to comply with the terms of any Third-Party Services used.
6. Client Responsibilities
   1. The Client represents that all information and materials provided are accurate and lawful. 
   2. The Client is responsible for final content approval, legal compliance of their business/content/data, and maintaining credentials and access after delivery. 
   3. Rewilt is not responsible for issues caused by Client-supplied content, instructions, or post-launch modifications.
7. Intellectual Property
   1. Upon full payment, the Client receives ownership or usage rights to deliverables as specified in the Project agreement. 
   2. Rewilt retains ownership of pre-existing frameworks, templates, processes, and know-how. 
   3. Rewilt may showcase non-confidential Project work in its portfolio unless otherwise agreed.
8. Confidentiality
   1. Both parties agree to keep confidential any non-public information exchanged. 
   2. Confidential information may be disclosed only where required by law or with prior written consent.
9. Limitation of Liability
   1. To the maximum extent permitted by law, Rewilt’s total liability arising from any Project shall not exceed the fees paid for that specific Project. 
   2. Rewilt shall not be liable for indirect, incidental, or consequential damages, including loss of profits, data, or business opportunities. 
   3. Nothing in these Terms limits liability for gross negligence, wilful misconduct, or mandatory statutory rights.
10. Force Majeure
    1. Rewilt shall not be liable for delay or failure caused by events beyond reasonable control, including but not limited to natural disasters, internet or power outages, third-party service failures, strikes, or government actions.
11. Independent Contractor Relationship
    1. Nothing in these Terms creates a partnership, joint venture, employment, or agency relationship between Rewilt and the Client.
12. Data Protection
    1. Personal data is processed in accordance with Rewilt’s Privacy Policy, which forms an integral part of these Terms.
13. Termination
    1. Either party may terminate a Project for material breach if such breach is not cured within a reasonable time.
    2. Upon termination, the Client remains liable for all completed milestones and work delivered up to the termination date.
14. Governing Law and Dispute Resolution
    1. These Terms are governed by Estonian law, without prejudice to mandatory protections under applicable law. 
    2. Parties agree to attempt good-faith resolution before initiating formal proceedings. 
    3. Any disputes shall be subject to the exclusive jurisdiction of the courts of Tallinn, Estonia, unless otherwise required by law.
15. Changes to These Terms
    1. Rewilt may update these Terms periodically. The “Effective Date” reflects the latest version. Continued use of services constitutes acceptance of updated Terms.
16. Contact
    1. Fromtribe OÜ (Rewilt) Lootsa tn 5, 11415 Tallinn, Estonia Registry No.: 17336307 Email: info@rewilt.com